Adjudication: Effective Dispute Resolution
|
1. AICA Rule 7(a) requires the referral to be served as soon as the adjudicator is appointed
2. Sherwood and Casson –v- McKenzie 30 November 1999
3. See Section 108(1) of the Act, paragraph 1(1) of the Scheme and paragraph 1 of the AICA Adjudication Rules by way of example. 4. Bech Peppiatt Limited –v- Norwest Holst Construction Limited
5. The Judge on this case was HHJ Frances Kirkham |
8. Although judges tend to give notices a “benevolent interpretation”6 , every care should be taken when drafting a notice. 9. With an Adjudicator’s decision, “If he has answered the right question in the wrong way, his decision will be binding. If he has answered the wrong question, his decision will be a nullity”7. It is the notice that must set the correct question. 10. The notice is not a formal document. The claimant can start an adjudication at any time and the claimant has control over what goes into the notice. The notice is a route map for the adjudication – it lists the issues which the adjudicator can look at. The adjudicator cannot stray outside the terms of the notice. The adjudicator is appointed to decide the dispute which is the subject matter of the notice and that notice determines his jurisdiction8 . …the scope of an adjudication is defined by the notice of adjudication…9 |
6. Judge Lloyd QC in David McLean v Swansea Housing 27 July 2001 , paragraph 12 7. Nikko Hotels (UK) Limited v MERPC Plc 1991 2EGLR 103 at page 108B approved by the Court of Appeal in Bougues UK Limited v Dahl–Jensen 31 July 2000 at paragraph 12 8. KNS Industrial v Sindall 17 July 2000 , paragraph 21 9. The Construction Centre Group Limited v The Highland Council – approving the same sentiments in the KNS case, Outer Court of Session, 23 August 2002, paragraph 19 |
...in the context of any notice of adjudication it is essential to inform the other party and the adjudicator of the basis upon which such claims are being made and which justifies these invoices, i.e. the statement of the nature of the redress, as required by the Scheme.10 11. A notice can be a simple document. At appendix B is a surprisingly short notice. The Scheme 12. The Housing Grants Act 1996 makes no mention of what should be included in a notice. Section 108(2)(a) merely states: “The contract shall…enable the party to give notice at any time of his intention to refer a dispute to adjudication.” When drafting a notice consideration needs to be given to the rules which govern the adjudication. Unfortunately different rules impose different requirements. 13. Part 1 of the Scheme for Construction Contracts (England and Wales Regulations 1998) does not leave drafting of the notice to chance. According to the Scheme, a notice
14. At appendix C is a notice which has been drafted in accordance with the Scheme. 15. Under the Scheme it is not enough for a notice merely to say that there has been a dispute in relation to an extension of time, set-off, variations, etc. and seek payment. A notice has to give details such as the parties involved, when and where the dispute arose, the “redress”, i.e. what the claimant wants the adjudicator to do, and the names and addresses of both parties to the contract. |
10. K&D Contractors v Midas Homes Limited, 21 July 2000
11. Paragraph 13 of the Scheme |
Notices under other adjudication rules 16. The AICA rules provide that the notice …shall state in sufficient detail the nature of the dispute and the remedy sought, together with a request to refer the dispute for Adjudication.12 Under the AICA rules, as well as the Scheme, the remedy must be specified. 17. TeCSA adopt a different approach. Here a notice must be served …identifying in general terms the dispute in respect of which adjudication is required.13 18. The Institution of Civil Engineers Adjudication Procedure has different requirements. Here the notice must give: 18.1 the details and date of the contract; 18.2 the issues which the adjudicator has been asked to decide; 18.3 details of the nature and extent14 of the redress sought. 19. CEDR ask for a copy of the Adjudication provisions in the contract15. 20. The JCT 1980 Form of Contract provides that a claimant need only ….give notice to the other Party of his intention to refer the dispute or difference, briefly identified in the notice…16 Jerome Engineering Limited v Lloyd Morris Electrical Limited 21. In this case17 the notice stated “…you have failed to properly make interim valuation and payment in accordance with clause 21.1 of the sub-contract”. The underlying contract was DOM /2, which had the same provisions as to what was to be included in the notice as JCT 80. Significantly, the notice made no mention of what the claimant wanted the adjudicator to do, i.e. award payment. |
12. See Rule 2(a) – emphasis added
13. TeCSA Rules, Rule 3
14. Institution of Civil Engineers Adjudication Procedure, paragraph 2.1 – emphasis added 15. ….and other information
16. Clause 41A.4.1 - emphasis added 17. 23 November 2001 |
22. However, under the DOM /2 form of contract the notice need only briefly identify the dispute or difference. The referral contained particulars of dispute or difference, sum of the contentions, etc, and a statement of the relief or remedy which was sought. Under DOM /2 form of contract the relief or remedy was to be stated in the referral , and not the notice. Accordingly, the notice in this case was still valid, even though it did not state what remedy the claimant wanted. 23. If, however, the adjudication was governed by the Scheme the Institution of Civil Engineers Adjudication Procedure or the AICA Adjudication Rules, the notice would have been invalid as it failed to state what the claimant wanted. 24. The Jerome Engineering case illustrates the importance of understanding some of the subtle differences governing notices between the various adjudication rules. Problem notices Vague notices 25. In Ken Griffin and John Tomlinson (trading as K&E Contractors) v Midas Homes Limited,18 the adjudication was subject to the Scheme which, as we have already seen, sets out a clear requirement as to what should be included in the notice. 26. In this case the notice stated:
27. The defendant’s solicitors in response stated:
28. The defendant refused to pay and when the claimant sought enforcement of the adjudicator’s decision. The court confirmed that the notice under the Scheme should record the dispute with some precision.
|
18. 21 July 2000
|
29. Here, there was a “range of possibilities”19. It was not clear whether the notice included damages for breach of contract, loss of profit, loss and expense, or loss as a result of terminating the contract. The judge, in view of the fact that the notice and ensuing adjudication were so vague, decided to enforce only the clear parts of the adjudicator’s decision and the sum awarded was reduced to just under £12,000. 30. However, adjudicators and judges alike can be sceptical of a party who is faced with a possibility of making a substantial payment alleging that the notice is vague. In one case it was stated:
Stating the remedy 31. Even if the remedy is not a necessary requirement of the Notice under rules which govern your adjudication, it is good practice to set the remedy out in a Notice. The remedy is in essence what the adjudicator is asked to do. 32. The adjudicator will normally look at the remedies asked for when finalising his decision to make sure he has answered all the key issues raised by the referring party.
|
19. Transcript page 7, paragraph C
20. Dean & Dyball Construction v Kenneth Grubb Associates Limited, 23 October 2003 , TCC |
33. In David McLean Housing Contractors Limited v Swansey Housing Association Limited21 the Scheme applied. The notice stated:
34. His Honour Judge Lloyd QC reiterated that the essential question was:
35. Whereas in this case a failure to state a remedy in an adjudication governed by the Scheme would cause a problem, here it did not as a result of the Defendant’s actions. Within a few days of the adjudicator’s award and a claim for a substantial sum, the employer issued a Withholding Notice deducting liquidated and ascertained damages reducing the amount due to the claimant under the adjudicator’s decision.
|
21. 27 July 2001 |
Essentially by acting in this way the employer accepted that the adjudicator had the right in the adjudication to award payment, even though payment was not one of the remedies specifically asked for in the notice.22 36. Some commentators have argued that the referral should include not only the referring party’s position, but a statement of the respondent’s position – thus setting out the “dispute” which includes both parties’ side of the story. I personally have never seen this done and am dubious of this approach as I doubt that a referring party can truly give the respondent’s position justice. Changing cases 37. Whilst Fastrack dealt with the issue that quantum changing in the run up to an adjudication, changing the actual items in dispute is a different matter. In Edmund Nuttall v R G Carter,23 the differences between the claimant preceded the adjudication and the Notice was as follows:- 38. Further, during the course of the adjudication, the claimants produced an Expert’s Report for the first time. The Report asked for the same extension of time of 235 days as per the original claim, but put forward a different justification. Some items were now said to have had no delaying effect and other items, according to the Expert’s Report, now caused significant delays. New items were introduced into the adjudication via the Report which had not featured in the claim at all. The claimants sought to rely upon Fastrack in the sense that the amounts claimed had changed and the other changes were questions of degree which did not prejudice the parties. 39. However, the court would not accept this agreement. His Honour Judge Seymour QC said that a party in an adjudication can refine its arguments and abandon points without fundamentally changing the nature of the “dispute”. What a party could not do was abandon wholesale facts relied upon and then advance new arguments for the first time in an adjudication. A party had to make claim which was then either rejected or ignored so as to turn it into a dispute that was capable of adjudication. If the adjudication was the first time the defendant had heard of the “claim” there could be no opportunity to reject or ignore it and therefore no dispute. 40. The Edmund Nuttall case was appealed but settled before the Court of Appeal gave its judgment. In a rare move the Court of Appeal issued an order indicating that although it did not have the opportunity to give judgment, there was a real prospect that the appeal would have been successful. 41. In the meantime the Edmund Nuttall case has caused considerable concern to adjudicators and parties. Cases often “develop” during an adjudication. The first time a party may see experts’ reports, witness statements, build-ups, etc. may be in the referral. There is a real question, and it is best a question of degree, as to how far a party can depart from what was being claimed in the adjudication. What should a notice contain? 42. This depends on the underlying adjudication rules. As a broad rule a notice should contain: 42.1 brief descriptions of the parties and the underlying contract; 42.2 brief description of the dispute; 42.3 a request for £x or such other sum as the adjudicator thinks is due to the claimant, together with interest for such period and at such rate the adjudicator thinks fit; 42.4 a request to be paid by x date or such other date as the Adjudicator thinks fit; 42.5 a request for payment of costs. If you are not entitled to your own costs, make sure you ask for the adjudicator’s fees to be paid by your opposite number or alternatively to be apportioned as the adjudicator thinks fit. Make sure you also claim the fee paid to the AICA for the appointment of the adjudicator. Adjudicator Nominating Bodies (“ANB”) 43. Please bear in mind the ANB only receives a form, a copy of the notice and on occasion a copy of the adjudication clause in the contract on which to base their decision to appoint an adjudicator. Therefore: 43.1 the form/covering letter needs to set out clearly why the adjudicator should be a quantity surveyor/barrister/undertaker, etc. 43.2 the referring party can speak to the ANB. This should not mean the ANB is placed under pressure to appoint a particular person – this is likely to be counter-productive. If there is a particular issue which should be brought to their attention, most appointing offices are willing to speak to the referring party on the telephone. Referral Preparation 44. It never ceases to surprise me how often referrals are served late. Whilst late service in itself may not invalidate the adjudication – see later. The referring party will have had many months to prepare his notice, referral, supporting documents, etc, but it does not reflect well on the referring party if the referral is served late. 45. I suggest the Referral is drafted first, and then followed by the notice. Only by drafting and agreeing the referral will the issues become clear. Further, by the time the notice is served and the adjudication started, the referral and all of the supporting documents should be ready, save for pagination and copying. Different rules, different Referrals 46. Once the notice has been served, the claimant then sets out his case in the referral. The referral is a detailed document explaining what the Claimant is entitled to, what he is claiming, and would normally include supporting documents and may even include experts’ reports, witness statements and whatever else the claimant decides to put in. The referral should follow on from the notice.
|
22. The David McLean decision turns on its own facts. Unless the adjudicator lacks jurisdiction, his decision must be complied with. However, here the adjudicator’s decision that the works should have been completed by X date meant that the claimant had not completed on time, and then under the terms of the adjudicator’s decision liquidated and ascertained damages were payable to the Employer. However, in the majority of cases it is difficult to resist a payment awarded by an adjudicator. 23. 21 March 2002
24. A novel phrase which lends itself to many jokes which I will not make here |
47. As with notices, different adjudication rules have different requirements for what should be put in the referral: 47.1 according to the Scheme, the referral is to be accompanied by copies of all relevant extracts from the construction contract and such other documents as the claimant relies upon.25 The referral is to be served within 7 days of the notice;26 47.2 the AICA Rules require the referral to be accompanied by copies of documents the claimant relies upon “suitably annotated”.27 Under the AICA Rules, the referral is to be served as soon as the adjudicator is appointed;28 47.3 the JCT form of contract requires the Referral to have
47.4 limiting the scope of the referral or setting out rules as to whether the referral (or notice) should be served is a common way of restricting the scope of adjudication.
48. There are ways round limiting the length of referrals and supporting documents: 48.1 whilst the referral may be very short, the main text of the claim etc is often put in another document; 48.2 any attempt to prevent the adjudicator from calling for additional information and documents is likely to contravene the requirement that the adjudicator can take the initiative and ascertain the facts and the law and the Scheme which requires the adjudicator to consider relevant documentation. Kitchen sink adjudications 49. A lengthy Notice is an appetiser for a rambling referral which is accompanied by lever arch files of documents, very few of which are relevant and many of which do not make sense. Although an adjudicator is empowered to take the initiative and ascertain the facts in the law, in these sorts of referrals it is difficult to work out precisely what is being claimed, asked for or supported, and the temptation is to drown under a sea of paperwork. 50. A claimant should try to: 50.1 set out his case clearly and to the point. This is very difficult to do as the points raised may develop during the course of an adjudication; 50.2 documents should be paginated! The referral should refer to the pagination numbers of the documents, this makes it far easier to follow; 50.3 resist the temptation to send large bundles of documents by way of “background” information. If a document is not mentioned in the referral, there is probably no need to include it. Helping the adjudicator understand your position 51. Bear in mind that the adjudicator will know nothing about the project, let alone the dispute, save for what he learns from the referral and the following submissions. The referral should follow events chronologically and refer to each sheet and paragraph within paginated bundles. Ignore the temptation to refer to a section within a lever arch file of documents and let the adjudicator try to find the relevant documents and paragraph you are referring to. The impact of your message will be lost whilst the adjudicator is trying to find the supporting evidence. 52. Also bear in mind how the presentation involved in the Referral will look to the adjudicator. I receive papers that have been crammed into overflowing files. Also, if (say) a contractor is alleging that the administration and the management of a project was run smoothly and efficiently, it hardly supports the contractor’s case when the referral makes little sense, has copies missing, is confusing, not paginated, etc. 53. Keep in mind human nature. If an adjudicator does not understand what is being said – he is likely to dismiss it. 54. I am dubious as to whether adjudication can be used for large-scale loss and expense claims. Frequently adjudicators can get lost in a wealth of detail and surrounded by a large number of lever arch files. I try to seek a series of selective adjudications in these circumstances wherever possible, such as whether one party has repudiated the contract. Or whether a particular item or items of works were variations. Time limits 55. When a notice or referral is served late, the responding party may argue that the notice/referral is invalid as it failed to comply with the time limits set down in the relevant adjudication rules - therefore the adjudicator has no jurisdiction to consider the notice/referral, late submission, etc. Two recent cases dealt with what happens when an adjudicator does not issue his decision within the required timescale. In both these cases when a draft decision was issued with the final decision following within a week or so, it was held that although the importance of complying with the time limit set down was important, the delays in issuing decisions which the adjudicator’s gave notice of, one of which was unavoidable due to the death of the adjudicator’s mother, did not render the decisions nullity. 56. I submit that the same applies to the parties’ submissions. Serving a submission one or two days late will not render nullity but the adjudicator should always look at the effect in serving the document late. Normally serving a referral a day or two later than planned can be cured by giving an extension to the other party. An adjudicator should, however, be weary of what happened in London & Amsterdam Properties Limited v Waterman Partnership Limited.31 Here the referring party served the supplemental statement with its enclosures which consisted of over 1,000 pages with only 7 days remaining in the adjudication process. The judge decided that this was “clearly deliberate” evidential ambush, and in this case there was insufficient time for the respondent to deal with the information, and the adjudicator had the power to exclude the new evidence. Jargon 57. Avoid it. Parties can “admit” a particular fact, but why not say this “agreed”? Why use “not admit” or “it is averred”? Clear English is more easily understood and within the time constraints of an adjudication is likely to have more impact. Defences No such thing as an ambush 58. As we have already seen the dispute and documents should have been sent to the responding party before an adjudication starts – there is no such thing as an ambush in adjudication. What is surprising, however, is when the responding party does little or nothing until they have actually received the referral. Admittedly, parties threaten adjudication regularly without carrying out the threat. If faced with a substantial financial dispute and a threat to adjudicate, the referring party should at the very least collate his documents personally, etc and get an idea of how he will deal with the inevitable claim. If any of the parties are given 7 days to submit a defence then the quality of the document will be poor if preparations only start once the referral is received. Setting out the Defence 59. Defences, like referrals, can be very confusing. The same rules apply to defences as to referrals – defences should be to the point, clear and include a paginated set of supporting documentation with the adjudicator being taken to the individual sheet and paragraph which the responding party is relying upon. 60. Nevertheless, I sometimes find it difficult to match up the allegations in the defence to the referral. Defences are prepared at speed and many respondents vent their anger in the defence. It is inevitable that the parties will be upset but I find that “loaded” language, ranting, etc only serves to confuse the adjudicator and detract from the main message that the respondent and indeed the referring party are trying to make. 61. At appendix D is a sample submission I send to the parties when sitting as an adjudicator. Essentially what I try to do is to ensure that the point I am making on behalf of the responding party immediately follows the point that was made by the respondent in the referral. This has two benefits: 61.1 it ensures that the responding party answers every point in the referral. 61.2 the defence is more likely to have more impact. The Adjudicator will read the referral and immediately hear what the responding party has to say about a particular point. Conclusion 62. Notices are relatively simple documents. Subject to complying with the underlying adjudication rules a notice should contain a brief description of the parties, the contract, the dispute, how much the claimant wants and give the adjudicator discretion to award a different amount. The notice should also have a request for interest and the adjudicator’s fee and nomination fee. 63. If a notice and the subsequent submissions are simple, they should be clear and easy to understand. 64. Prepare. Have the referral and the supporting documents ready before the notice is served. Don’t be afraid to speak to the ANB.
|
25. Paragraph 7(2) 26. Paragraph 7(1) 27. Rule 7(b) 28. Paragraph 7(b)
29. Clause 41A.4.1
30. Solland International v Daraydan Holding, 15 February 2002
31. 18 December 2003 |
Appendix B The Contractor Today’s date
Dear Sir Tower of London32 We refer to Interim Application No. 12 for £150,000 plus VAT. As of today’s date, you have only paid £100,000. This, according to you, is due to the allegation that we delayed the works and you are entered to deduct £50,000 liquidated and ascertained damages. We deny that the works are delayed and we hereby request the dispute our entitlement to an extension of time as to payment of £50,000 (or such other sums which the Adjudicator finds is due) as a result of delays to the works from Interim Payment No.11 be referred to adjudication. We will also be asking for interest on the sums due to us. We are applying to the AICA for the appointment of an Adjudicator today. Yours faithfully
Sub Contractor
Appendix C
IN THE MATTER OF THE HOUSING GRANTS, CONSTRUCTION AND REGENERATION ACT 1996 AND IN THE MATTER OF AN ADJUDICATION
BETWEEN:
CONTRACTOR CONSTRUCTION LIMITED(The Referring Party)
- AND -
EMPLOYER PLC (The Responding Party)
NOTICE OF ADJUDICATION
INTRODUCTION1. On or about 23 October 2004 Contractor Construction Limited (“Contractor”) entered into a contract with Employer Plc (“Employer”) for the supply and installation of WC Fit Out Works Package 837687436 at 54 The Lane, London, WC10 8KB (“the Works”). The Contract was based upon Employer’s Purchase Order Conditions as amended. The Sub-Contract Price was £957,133.41. THE NATURE AND A BRIEF DESCRIPTION OF THE DISPUTE AND OF THE PARTIES INVOLVED 2. During the course of the Works disputes have arisen regarding:-
DETAILS OF WHERE AND WHEN THE DISPUTE HAS ARISEN 3. The dispute arose in connection with Employer’s offices at 54 The Lane on or between 16 October 2004 and March 2005. THE NATURE OF THE REDRESS WHICH IS SOUGHT 4. Contractor seek a decision from the Adjudicator that:-
THE NAMES AND ADDRESSES OF THE PARTIES TO THE CONTRACT (including where appropriate, the addresses which the parties have specified for the giving of notices) 5. Contractor’s full name and address is:
6. Employer’s full name and address is:
7. Under Clause 41 of the Contract, all Notices are to be given to Employer’s and Contractor’s Registered Offices. Both parties’ registered offices are as above. Contractor ask all matters relating to this adjudication be sent to their solicitors, Fenwick Elliott, whose details appear below.
SERVED on 26 May 2005 by Fenwick Elliott, 353 Strand , London , WC2R 0HT , Tel: 020 7956 9354, Fax: 020 7956 9355; email jmiller@fenwickelliott.co.uk (contact Jon Miller) Solicitors to Contractor Construction Limited. Appendix D
IN THE MATTER OF THE HOUSING GRANTS, CONSTRUCTION AND REGENERATION ACT 1996 AND IN THE MATTER OF AN ADJUDICATION B E T W E E N: Sub-Contractor Referring Party and Main Contractor Respondent Sub-Contractor’s Referral served on 1 January 2005
[***dd/mm/yy] (1) Contractor’s Response served on 15 January 2005 [***dd/mm/yy] (2)
Background 1. On or about 1 January 2004 the Sub-Contractor entered into a Sub-Contract (“Sub-Contract”) with [The Contractor] to install mechanical services in connection with the refurbishment of new offices, London, WC1 (See Documents1-14)(1). 1.1 Agreed, save that the contract areas entered into on 2 January 2004 (2). 2. The Sub-Contractor submitted accounts for payment of its fees under the terms of the Sub-Contract. In particular, the Sub-Contractor issued accounts on 1 March and 1 April 2004 which to date have not been paid by the Contractor.(1) 2.1 The accounts were not submitted in accordance with the Sub-Contractor. More details are given in paragraph 23.1 below(2). 3. The background to this matter and the details raised in this dispute are set out in the statement of Mr Smith, who is the site manager of Sub-Contractor (see Documents 15-22)(1). 3.1 The facts in Mr Smith’s statement are denied, see Mr Jones’ statement (see Documents 201-205)(2). 4. On [***dd/mm/yy] [***Referring Party’s expert/witness] was contacted by [***Respondent’s expert/witness] (see Document [***]), who are [***job title] appointed by [***Respondent] (see Document [***]) and acting as [***Respondent]’s agent for the appointment of consultants and professionals. [***Referring Party] was asked to provide a report on the Planning use and Means of Escape of the premises leased by [***Respondent] .(1)….etc, etc….. 4.1 Correct. (2)
[***…….and so on. Any comments which do not fit this format can be included in a “General” section at the back]
Dated [***] Contacts [***] Referring Party [***] Responding Party |
32. This is a very simple notice. Some adjudication rules require far more detail. |
Author ProfileJon Miller was originally an apprentice with Matthew Hall Mechanical and Electrical Engineers Limited. In 1981 he left Matthew Hall to re-enter full-time education, qualifying as a solicitor in 1989. Since then, Jon has been exclusively involved in the law relating to construction and engineering matters. Jon is a Fellow of the Chartered Institute of Arbitrators, an Associate of the Chartered Management Institute, and Academy of Experts and TeCSA accredited mediator, holds an MSc (Construction Law and Arbitration), is a RIBA, TeCSA, AICA and CIC Adjudicator. Jon lobbied the House of Lords on behalf of the construction industry during the passing of the Housing Grants etc Bill and prepared the first draft of adjudication rules for two adjudicator nominating bodies. As well as resolving disputes via adjudication, mediation, litigation and arbitration, Jon has also drafted construction contracts, bonds, warranties and guarantees. He was responsible for drafting the agreements relating to CTRL and West Coast Mainline. Jon is board member of the Chartered Management Institute (London Branch) and the Chartered Institute of Arbitrators (London Branch). Jon is a solicitor and partner with Fenwick Elliott LLP.
|
|